中国潜水打捞行业协会沉船打捞标准合同--中英文.docx

《中国潜水打捞行业协会沉船打捞标准合同--中英文.docx》由会员分享，可在线阅读，更多相关《中国潜水打捞行业协会沉船打捞标准合同--中英文.docx（39页珍藏版）》请在淘文阁 - 分享文档赚钱的网站上搜索。

1、?中国潜水打捞行业协会沉船打捞合同?总承包价分付款_年_月_日 _签署地 以下称 以下称打捞方同意签订本合同本合同于 年 月 日生效。双方同意按本合同规定的条款打捞本合同第一条所述的船舶。 1. 船舶船名 船籍 注册地 总长/型宽/型深 设计吃水 总吨/净吨/载重吨 货物详情和性质 船舶位置、状态及作业工地情况 本合同中术语“船舶应包括任何性质的船舶、艇筏、财产或其部件包括装载于其中或其上的任何物品诸如但不限于本条描绘的货物和燃料。2效劳打捞方同意在履行合同时做到应有的慎重并尽量在0条规定的地点交付或处置船舶。在与合同中约定的效劳性质不起冲突的前提下打捞方要以应有的慎重防止和减小对环境造成的危

2、害。打捞方应提供本合同附件1所载明的人员、船艇、设备这些人员、船艇设备应当是打捞方根据船舶状况、位置以及工地情况认为在效劳过程中所必须使用的。打捞方的作业应按照附件2的约定并且应当使用附件1中列明的人员船艇和设备。3价格和支付条款31 打捞总承包价大小写： 3. 2 延误费率: 元/天33 支付方式：第一 第二 第三 第四 34 所有向打捞方支付的款项应按照以下约定的银行帐户和货币进展支付：行: 名: 帐: 货币 : 3. 5总承包价的每付款都应按本合同约定在合理限内完全并不可撤销地由打捞方获得。本合同下所有应向打捞方支付的费用应该没有任何折扣、扣除、抵销、留置、索赔或者反索赔。3. 6根据本

3、合同支付的所有款项打捞方应尽快给开具。假设打捞方在合同约定限的3个银行工作日内未收到应支付的款项那么该款项应按年息 记取利息。3. 7假设在约定限7日内未支付合同应付款项或者应打捞方的要求根据2条需要的担保未在5个银行工作日内提供打捞方可以在以后的任何时间在不损害本方已得费用及所享有的进一步对的权利或救济的情况下终止本合同。但是打捞方对其行使救济权利应至少提早3个工作日。4代表 在作业过程中应打捞方的合理要求应当有一名全权代表随时在场。应尽可能向打捞方提供所要求的一切信息。 另外应在自己承担风险和费用的情况下提供足够的高级船员或同等资质人员这些人员应熟悉货物体系和船舶布置情况并在作业过程中应打

4、捞方的合理要求在现场以便为打捞方提供作业建议。5作业 和(或)人员、船艇和设备的调整51 假设在履行合同前或履行间由于以下原因需要对本合同项下的效劳或人员、船艇、以及设备进展本质性的调整那么打捞方应该书面并告知其为完成效劳而估计增加的额外费用这种调整非因打捞方的过失：511由于的忽略打捞方在作业时所根据的材料或数据错误；512船舶或者作业工地的位置情况有重大变化。52 双方应不延迟地对承包价上增加的额外费用进展协商并达成协议。 假设在打捞方提供额外费用的5天内双方不能达成一致协商那么在不损害第511条打捞方索赔权利的情况下任何一方都有权终止本合同下的效劳但是必须征得主当的同意。此情况下打捞方有

5、权根据本合同的规定在终止时获得全部应得费用。 假设主当不同意终止合同应随时按照第3条规定的延误费率向打捞方支付费用。有责任向打捞方支付持续提供效劳所发生的合理且必要的费用。53就额外费用的合理性和金额根据合同的条款双方也可以协商将此提交仲裁以获得仲裁员的裁决(仅在17.1条被选用时适用)。在提交仲裁的过程中打捞方应继续提供本合同下的效劳同时保存其对额外费用的索赔权。5. 4 在合同履行前或履行间假设船舶或者作业工地的位置情况发生重大变化导致原打捞方案见附件2无法施行打捞方有权变更方案但打捞方应将方案的变更情况书面。6其他约定61应该安排所需的船舶设标和警告并支付相应费用。打捞方应该安排作业间本

6、方设备所需的设标和警告并支付相应费用。62打捞方在履行合同间或为了到达合同目的可以合理地使用船舶机械、索具、设备、锚、链、贮藏品以及其他附属品但不能对财产标的做出不必要的损坏、弃置或者抛弃。63在获得同意 (不得不合理地回绝)并征得主当的容许的情况下假设打捞方认为是为完成合同目的所合理必须的打捞方有权从船舶上移除、处置或者抛弃货物、船舶部件或设备。 64应打捞方的要求应向打捞方提供船舶图纸货物舱单积载图纸等资料。7容许证 /打捞方应当获得并持有为履行合同目的所需的执照、批准书、资质证书、授权书或容许证同时支付相关费用。另一方应在获得容许证方面提供合理帮助。8延误 假设在履行合同间打捞方由于、效

7、劳人员或代理人违犯合同、忽略或任何其它过失或由于任何打捞方所不能控制的其它原因导致效劳及与之有关的工作那么在延误间应按照第3条第2款所列的延误费率给予打捞方补偿缺乏一天按适当比例计算。 打捞方应将所有延误情况及时告知应尽快以书面形式确认实际发生的延误情况。 9终止91在打捞方的人员、船艇、设备调遣开始之前有权随时终止合同。终止时应支付 的终止合同费用。92在履行合同时或进展第5条双方同意的调整时打捞方在技术上和上已经无法继续进展在征得同意后(不得不合理地回绝)打捞方可以终止合同且不承担责任终止合同时打捞方有权根据本合同获得所有应得费用。93假设主不允许暂停或者终止合同应当按照第3条规定的延误费

8、率在打捞方待命间向打捞方支付人员、船艇和设备的费用。同时应当向打捞方支付因持续提供效劳而产生的合理且必要费用。10船舶交付101 交船地点： 10. 2 或其授权代表应当在收到打捞方的书面交船后 小时内在交船地点承受并且接收船舶。 船舶交付地点对打捞方自有或者租用的船艇以及船舶的进入和操作应该是平安的并且应该是打捞方经或者相关当允许交付或者处置船舶的地方。 假设在收到打捞方书面交船后 小时内没有承受船舶或者由于打捞方所不能控制的或者相关部门的行为致使船舶交付受到阻止或者延误应由承担从预计交付之日起打捞方发生的所有必要费用且应该在第3条指定的延误支付费用上进展追加。10 3 假设打捞方认为无法在

9、交船地点交付或处置船舶或认为交船地点不平安且未指定替代交付地点那么打捞方在无不合理延误的情况下有权在其可以平安到达的最近地点交付船舶。一旦交付或处置船舶后可视为已经履行了应有的合同义务。 应按照第3条规定的延误费率并根据此款所使用的额外时间对打捞方予以补偿并应对打捞方在此款规定下发生的任何额外费用负责。10. 4 假设船舶是在泵和(或) 空压机或者其他设备的控制下交付那么应做出适当派遣安排己方设备和操作人员交换打捞方的设备和操作人员。 交换完成后应按照合理费率支付给打捞方自船舶交付之日起至打捞方设备和人员返回打捞方基地之日止(包括到达日)的打捞方设备和人员的使用费用及与此相关的其它额外费用。1

10、0. 5效劳完毕后假设在打捞方提供书面交付书后5日内没有及时承受船舶或者打捞方认为船舶可能会恶化腐烂变得没有价值或者会产生超过船舶价值的仓储或其它费用打捞方可以不经且不产生任何责任的变卖或者处置船舶变卖船舶所得应返还给并可将收益冲抵应支付给打捞方的费用。本条款不影响打捞方所享有的对的其它索赔权利。 假设上述变卖所得缺乏以支付打捞方的应得费用仍应支付缺乏部。10. 6 船舶交付应包括船舶部件、船上的货物以及船舶上的其他物件并且可以在不同时间、不同地点进展交付。11额外费用 以下所有的费用本钱当其到时应该由支付：111所有港口费用、引航费用、港务和运河费以及对打捞方拥有或者租用的船艇进展征收或者应

11、支付的所有其他相似性质的费用。112当打捞方合理认为是必要的或者由港口、其他当规定的辅助拖轮的效劳费用；113所有与港口手续、代理、签证、担保有关的费用以及所有类似的费用。114所有税费、社会治安防卫费用(非打捞方在其主要营业地点所在国正常交纳的费用)、印花税或者与本合同有关的其它应征收的费用、进出口税和海关关税；115在履行合同时所发生的超出打捞方合理费用以外的应、相关当要求而发生的费用。116在对船舶进展处置或其他作业时承包方合理消耗的便携式救助设备、材料或者储藏品的所有费用。 假设以上费用实际上已经由打捞方或者打捞方代表进展了支付在收到打捞方时应根据打捞方实际发生的费用补偿给打捞方。12

12、担保 应在签署本合同时以双方协商同意的形式和数额提供不可取消和无条件的担保。假设在签署合同时未约定担保但事后打捞方要求做出担保那么应当对应付或将付款项的全部或部以双方协商同意的形式和数额提供担保或者进一步担保。 应打捞方要求这种担保应一次或者屡次予以提供。13责任1311在履行合同间由于以下人员的伤亡所裁定的应负责任或经过合理调解的索赔应保障打捞方不受损害：的效劳人员或其代理人；代表或应的恳求不何种目的处在或靠近作业工地的其他人员。1312在履行合同间由于以下人员伤亡所裁定应负责任或经过合理调解的索赔打捞方应保障不受损害：打捞方的效劳人员或其代理人；代表打捞方或应打捞方的恳求不何种目的处在或靠

13、近作业工地的其别人员。1321及其效劳人员和代理人对打捞方所有或租用的船艇或设备(不包括在对船舶处置或其他作业间合理消耗的可携带的救助设备、材料或储藏品)遭受的任何性质的损失或损坏不负任何责任不这种损失或损坏是否由于及其效劳人员和代理人违犯合同、忽略或其它过失所致。1322打捞方及其效劳人员和代理人对船舶所遭受的任何性质的损失或损坏包括但不限于船体变形、构造损坏等不负任何责任不这种损失或损坏是否由于打捞方及其效劳人员和代理人违犯合同、忽略或其它过失所致。1331 在履行合同间应负责并同意保障打捞方免受不任何原因导致的由船舶产生的实际的或潜在的任何污染损害引起的索赔、本钱、费用、行为、诉讼、要求

14、和责任。1332 在履行合同间打捞方应负责并同意保障免受不何种原因导致的由打捞方自己或租用的船艇产生的实际的或潜在的污染损害所引起的索赔、本钱、费用、行为、诉讼、要求和责任。134 除非本合同有其他额外规定或打捞方对任何原因引起的另一方的利润损失、使用损失、消费损失或其它间接损失不负有责任。14喜玛拉雅条款本合同规定的有利于打捞方或的全部例外、豁免、辩护、免除、责任限制、赔偿、优惠和条件将同样适用于打捞方或各自的分包人、经营人船东(假设是光船承租人)、船长、高级船员和船员；也适用于各自的母、子、分或与其在同一理下的所有法人团体以及团体中的全部董事、高级职员、工作人员和代理人；也适用于代表双方实

15、行合同的所有工作人员代理人和分包人。打捞方或应充当上述人员、实体和船舶的代理人或受托人并代表他们的利益但目的仅限于为了将利益扩大给上述人员、实体和船舶。15留置权 在不损害打捞方享有的对人或物的权利的情况下打捞方为了获得合同中的应得款项有权对船舶行使留置权在行使留置权的过程中有权占有船舶财产。同时打捞方或其代表在执行留置权时不何种原因所产生的本钱和费用都应当支付给打捞方。16诉讼时效任何由本合同引起的或与本合同有关的争议或由履行合同所引起的索赔应以电传、 、电报或其它书面形式被索赔方要在完成效劳或效劳终止后的12个月内或在第三方提出索赔恳求的12个月内提出(以较迟者为准)。诉讼应当在向被索赔方

16、提出索赔恳求的一年内提出。否那么将会失去本合同下的索赔权利和诉讼权利。17适用法律和辖 本合同受法律辖并据此解释；由本合同引起的争议应由合同双方友好协商解决如协商不成那么按以下方式解决(二者选一)：17. 1 提交中国海事仲裁会在北京按其仲裁规那么仲裁。17. 2向 海事提起诉讼。 签字： 签字打捞方：?中国潜水打捞行业协会沉船打捞合同? (总承包价分付款) -人员、船艇、设备细目表 ?中国潜水打捞行业协会沉船打捞合同?(总承包价分付款) 附件2-打捞方案 ina Diving and Salvage Contractors Association (CDSCA) Wreck Removal

17、AgreementLump Sum Stage Payments Date: Place: This Agreement is entered into by and between (hereinafter referred to as “the pany) and (hereinafter referred to as “the Contractor) and is effective this day of .The pany and the Contractor mutually agree to remove the vessel stated in Clause 1 subject

18、 to terms and conditions hereunder1. The Vessel Name Flag Place of Registry Length/Beam/Depth Maximum Draft GT/NT/DWT Details and Nature of Cargo Position and Conditon of Vessel, Condition of Worksite The term Vessel shall include any vessel, craft, property or part thereof of whatsoever nature, inc

19、luding anything contained therein or thereon, su as but not limited to cargo and bunkers, as described in this Clause2. The Services The Contractor agrees to exercise due care in performance of this Agreement, and will endeavour to deliver or dispose of the Vessel at the place indicated in Clause 9

20、Insofar as it is not inconsistent with the nature of the services to be rendered under this Agreement, the Contractor will also exercise due care to minimize damage to the environmentThe Contractor shall provide the Personnel, Craft and Equipment set out in Annex I of this Agreement whi the Contract

21、or deems necessary for the services based on the Specifications, Condition and Position of the Vessel and Worksite. The Contractors Method of Work shall be as described in Annex II, utilising the Personnel, Craft and Equipment described in Annex I.3 Price and Conditions of Payment31 Lump Sum Price (

22、in figures and s)： 32 Delay Payment Rate： 33 Payments：1st Installment 2nd Installment 3rd Installment 4th Installment 34 All payments to the Contractor shall be made in the currency and to the bank account stipulated hereunderBank： Account Name： Account Number： Currency： 3 5 Ea installment of the lu

23、mp sum shall be fully and irrevocably earned at the moment it is due as set out in this Clause All monies due and payable to the Contractor under this Agreement shall be paid without any discount, deduction, set-off, lien, claim or counterclaim36 The Contractor shall promptly invoice the pany for al

24、l sums payable under this Agreement If any sums whi bee due and payable are not actually received by the Contractor within 3 banking days after due, they shall attract interest at annual rate of _37 If any amount payable under this Agreement has not been paid within seven (7) days of the due date, o

25、r if the security required in accordance with Clause 12 is not provided within five (5) banking days following the request by the Contractor, then at any time thereafter the Contractor shall be entitled to terminate this Agreement without prejudice to the sums already due to the Contractor and to an

26、y further rights or remedies whi the Contractor may have against the pany Provided always that the Contractor shall give the pany at least three (3) working days notice of its intention to exercise this right4 pany Representative If reasonably required by the Contractor a representative of the pany

27、will be available during the operations with the full authority to act on behalf of the pany The pany will use its best endeavours to provide all information required by the ContractorIn addition, the pany will provide at its sole risk and expense sufficient officers or their equivalents, who are fu

28、lly conversant with the cargo system and layout of the Vessel, and who should be in attendance when reasonably required during the operations in order to provide advice as and when requested by the Contractor5 ange of Method of Work and/or Personnel, Craft and Equipment51 The Contractor shall forthw

29、ith give notice in writing thereof to the pany and of the estimated additional costs to effect the services, if before or during performance of this Agreement, , there is a substantial ange in the work to be done under this Agreement, or in the Personnel, Craft and Equipment required to undertake th

30、e services due toprovided always that su anges are not caused by fault on the part of the Contractor:511 any error in the information or specification on whi the Contractor has relied caused by the neglect of the pany.512 a material ange in the position and/or condition of the Vessel or the worksite

31、.52 The parties shall, without delay, consult ea other to rea agreement on the amount of the additional costs to be added to the Lump SumIn the event that the parties are unable to rea agreement on the additional costs within 5 days of the Contractor providing details of the extra costs, either part

32、y may terminate the services under this Agreement, without prejudice to any claim the Contractor may have under Clause 511 , provided always that su termination is permitted by the petent authorities In su event the Contractor is entitled to be paid all sums due at the time of termination in accorda

33、nce with this agreementIf permission to terminate is not given by the petent authorities the Contractor shall be paid by the pany at the Delay Payment Rate set out in Clause 3 during any standby period, and the pany shall be liable for the Contractors reasonable and necessary costs of continuing wit

34、h the services5 3 Alternatively the parties may by agreement refer the matter to Arbitration in accordance with the provisions of this Agreement for a decision by the Arbitrator on the reasonableness and quantum of su extra costs (only applicable when Clause 17.1 is selected).In the event the matter

35、 is referred to Arbitration the Contractor will continue to provide the services hereunder, without prejudice to his claim for additional remuneration.5 4 Before or during performance of this Agreement, if the method of work (as specified in Annex II) can not be carried out as a result of a material

36、 ange in the position and/or condition of the Vessel, or the worksite, the Contractor is entitled to ange the method of work provided always that notice in writing of su anges of the method of work is given to the pany by the Contractor6Miscellaneous61 The pany shall arrange and pay for any marking

37、of the Vessel and cautioning required The Contractor shall arrange and pay for any marking or cautioning required in respect of its own equipment during the services under this Agreement 62 The Contractor may make reasonable use of Vessels mainery, gear, equipment, anors, ains, stores and other appu

38、rtenances during performance of and for the purposes of this Agreement free of expense but shall not unnecessarily damage, abandon or sacrifice any property the subject of this Agreement63 Subject to approval of the pany, whi shall not be unreasonably withheld, and subject to it being permitted by the petent authorities, the Contractor shall be entitled to remove, dispose or jettison cargo, or parts of the Vessel or equipment from the Vessel if su action is conside