菲迪克FIDIC简明合同格式中英对照版.doc

《菲迪克FIDIC简明合同格式中英对照版.doc》由会员分享，可在线阅读，更多相关《菲迪克FIDIC简明合同格式中英对照版.doc（25页珍藏版）》请在淘文阁 - 分享文档赚钱的网站上搜索。

1、菲迪克(FIDIC)简明合同格式-中英对照版菲迪克（FIDIC）文献译丛 中英文对照本国际咨询工程师联合会编译中国工程咨询协会1999年第1版Agreement协议书General Conditions通用条件Rules for Adjudication裁决规则Notes for Guidance指南注释Short Form of Contract简 明 合 同 格 式吕文学陈永强翻译唐 萍校译王 川徐礼章唐 萍审订（1999年第1版）（中英文对照本）（译者对译文准确度承担全部责任，正式使用发生争端，以英文原版为准）机 械 工 业 出 版 社菲迪克（FIDIC）授权书I herewith au

2、thorize CNAEC to translate FIDICs publications (but not the publications as edited by other organizations) into Chinese and publish them.I agree with your statement, as part of the agreement, that you will:a) Provide FIDIC with 10 copies of the translation per document, and b) Make a statement on th

3、e inside cover of the translation that the translator takes full responsibility for the accuracy of the translation and that in case of dispute, the original version in English shall prevail.Peter van der TOGTPublications manager译文在此，我授权中国工程咨询协会把FIDIC出版物译成中文并出版（但是，不包括其他组织编写出版物）。我同意你们意见，作为协议一部分，你们应：a

4、) 向FIDIC提供每份文件中译本10本；b) 在译文扉页上注明译者对译文准确度承担全部责任，如果发生争端，以英文原版为准。出版经理：Peter van der TOGTFIDIC is the French acronym for the International Federation of Consulting Engineers.FIDIC （中译菲迪克）是国际咨询工程师联合会法文缩写。FIDIC was founded in 1913 by three national associations of consulting engineers within Europe. The o

5、bjectives of forming the federation were to promote in common the professional interests of the member associations and to disseminate information of interest to members of its component national associations.菲迪克（FIDIC）是由欧洲三个国家咨询工程师协会于1913年成立。组建联合会上是共同促进成员协会职业利益，以及向其成员协会会员传播有益信息。Today FIDIC membersh

6、ip numbers more than 60 countries from all parts of the globe and the federation represents most of the private practice consulting engineers in the world.今天，菲迪克（FIDIC）已有来自全球各地60多个国家成员协会，代表着世界上大多数私人执业咨询工程师。FIDIC arranges seminars, conferences and other events in the furtherance of its goals: mainten

7、ance of high ethical and professional standards; exchange of views and information; discussion of problems of mutual concern among member associations and representatives of the international financial institutions; and development of the consulting engineering industry in developing countries.菲迪克（F

8、IDIC）举办各类研讨会、会议及其他活动，以促进其目标：维护高道德和职业标准；交流观点和信息；讨论成员协会和国际金融机构代表共同关心问题，以及发展中国家工程咨询业发展。FIDIC publications include proceedings of various conferences and seminars, information for consulting engineers, project owners and international development agencies, standard pre-qualification forms, contract docu

9、ments and client/consultant agreements. They are available from the secretariat in Switzerland.菲迪克（FIDIC）出版物包括：各类会议和研讨会文件，为咨询工程师、项目业主和国际开发机构提供信息，资格预审标准格式，合同文件以及客户与工程咨询单位协议书。这些资料可以从设在瑞士菲迪克（FIDIC）秘书处得到。国际咨询工程师联合会INTERNATIONAL FEDERATION OF CONSULTING ENGINEERSFOREWORD 前言These Conditions of Contract ha

10、ve been prepared by the INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS （FIDIC）and are recommended for engineering and building work of relatively small capital value. However, depending on the type of work and the circumstances, the Conditions may be suitable for contracts of greater value. They a

11、re considered most likely to be suitable for fairly simple or repetitive work or work short duration without the need for specialist sub-subtract.国际咨询工程师联合会（FIDIC菲迪克）已编写本合同条件，建议用于投资金额相对较小工程项目和建筑工程。根据工程类型和具体情况，也可以适用于金额较大合同。本条件可能最适用于不需进行专业分包相当简单或重复性工程或工期短工程。The main aim has been to produce a straightf

12、orward flexible document which includes all essential commercial provisions and which may be used for all types of engineering and building work with a variety of administrative arrangements. Under the usual arrangements for this type of contract, the Contractor constructs the Works in accordance wi

13、th design provided by the Employer or by his representative (if any). However, this form may also be suitable for contracts which include, or wholly comprise, contractor-designed civil, mechanical and/or electrical works.主要上是编出一个简明、灵活文件，包括所有主要商务条款，可用于多种管理方式各类工程项目和建筑工程。这种合同通常情况是，由承包商按照雇主或其代表（如果有）提供设计

14、实施工程。这种格式也可用于包括或全部由承包商设计土木、机械和/或电气工程合同。In addition, the Employer has a choice of valuation methods. Furthermore, although there is no reference to an impartial Engineer, the Employer may appoint an independent Engineer to act impartially, should he wish to do so.另外，雇主可以选择估价方法。还有，尽管没有提到公正工程师，如果雇主想聘用一

15、个独立工程师公平行事，他可以这么做。The form is recommended for general use, though modifications may be required in some jurisdictions. FIDIC considers the official and authentic text to the version in the English language.建议本格式可供通用，便在某些司法管辖区可能需要一些修改。菲迪克认为正式和权威性文本应是英文版本。The intention is that all necessary informatio

16、n should be provided in the Appendix to the Agreement, the latter incorporating the tenderers offer and its acceptance in one simple document. The General Conditions are expected to cover the majority of contracts. Nevertheless, users will be able to introduce Particular Conditions if they wish, to

17、cater for special cases or circumstances. The General Conditions and the Particular Conditions will together comprise the conditions governing the rights and obligations of the parties. 编写意图是所有必要信息应在协议书附录中给出，协议书把投标人报价和雇主接受编入一个简单文件。通用条件应能覆盖多数合同，如果用户需要，他们可以加入专用条件以适应特定情况或条件需要。通用条件和专用条件将一起构成决定各方权利和义务条件。

18、To assist in the preparation of tender documents using these Conditions, Notes for Guidance are included. These Notes will not become one of the documents forming the Contract. Finally, applicable Rules for Adjudication are also included.为了有助于使用本条件编制招标投标文件，还包括了指南注释。这些注释不是组成合同一个文件。最后，还列入了适用裁决规则。The a

19、ttention of users is drawn to the FIDIC publication “Tendering Procedure”, which presents a systematic approach to the selection of tenderers and the obtaining and evaluation of tenders.用户请注意菲迪克（FIDIC）编写出版招标程序，它提供了选择投标人、招标和评标系统方法。目 录Agreement 协议书6Offer报价6Acceptance 接受6Appendix 附录7General Conditions

20、通用条件91 General Provisions 一般规定91.1 Definitions 定义91.2 Interpretation 解释111.3 Priority of Documents 文件优先次序111.4 Law 法律111.5 Communications 通信交流111.6 Statutory Obligations 法定义务112 The Employer 雇主122.1 Provision of Site 现场提供122.2 Permits and Licences 许可和执照122.3 Employers Instructions 雇主指示122.4 Approval

21、s 批准123 Employers Representatives 雇主代表123.1 Authorized Person 受权人123.2 Employers Representative 雇主代表134 The Contractor 承包商134.1 General Obligations 一般义务134.2 Contractors Representative 承包商代表134.3 Subcontracting 分包134.4 Performance Security 履约担保135 Design by Contractor 由承包商设计145.1 Contractors Design承

22、包商设计145.2 Responsibility for Design146 Employers Liabilities 雇主责任146.1 Employers Liabilities 雇主责任147 Time for Completion竣工时间157.1 Execution of the Works工程实施157.2 Programme进度计划167.3 Extension of Time延长期167.4 Late Completion 延迟竣工168 Taking-Over接收168.1 Completion竣工168.2 Taking-Over Notice 接收通知169. Reme

23、dying Defects修补缺陷179.1 Remedying Defects修补缺陷179.2 Uncovering and Testing除去覆盖和试验1710. Variations and Claims变更和索赔1710.1 Right to Vary变更权1710.2 Valuation of Variations 变更估价1810.3 Early Warning提早通知1810.4 Right to Claim索赔权1810.5 Variation and Claim Procedure变更和索赔程序1811. Contract Price and Payment合同价格和付款1

24、911.1 Valuation of the Works 工程估价1911.2 Monthly Statements 月报表1911.43 Interim Payment期中付款1911.4 Payment of First Half of Retention前一半保留金支付1911.5 Payment of Second Half of Retention后一半保留金支付2011.6 Final Payment最终付款2011.7 Currency 货币2011.8 Delayed Payment 延误付款2012. Default 违约2012.1 Default by Contracto

25、r2012.2 Default by Employer雇主违约2112.3 Insolvency 无力偿债2112.4 Payment upon Termination终止付款2113. Risk and Responsibility 风险和职责2213.1 Contractors Care of the Works 承包商工程照管2213.2 Force Majeure 不可抗力2214. Insurance 保险2314.1 Extent Cover 保险范围2314.2 Arrangements 约定2314.3 Failure to Insure 未能办理保险2415. Resolut

26、ion of Disputes 争端解决2415.1 Adjudication 裁决2415.2 Notice of Dissatisfaction 表示不满通知2415.3 Arbitration 仲裁25Particular Conditions 专用条件25Agreement 协议书The Employer is of The Contractor is of The Employer desires the execution of certain Works known as 雇主是： 承包商是： 雇主要实施工程名称为 Offer报价The Contractor has examin

27、ed the documents listed in the Appendix which forms part of this Agreement and offers to execute the Works in conformity with the Contract for the sum of (in words) (in figures) ( ) or such other sum as may be ascertained under the Contract.This offer, of which the Contractor has submitted two signe

28、d originals, may be accepted by the Employer by signing and returning one original of this document to the Contractor before (date) The Contractor understands that the Employer is not bound to accept the lowest or any offer received for the Works.Signature: Date: Name: Authorized to sign on behalf o

29、f (organization name): Capacity: 承包商已研究了构成本协议书一部分列于附录中文件，按照合同实施该工程所报价格为 (大写) (小写) ( ) 或根据合同可能确定此类其他总额。承包商已提交两份本报价签字原件，雇主可通过签字和将本文件一份原件于 (日期)前返还给承包商予以接受。 承包商理解雇主不一定必须接受收到对该工程最低或任何报价。签字： 日 期： 姓名： 受权代表： （组织名称） 签字职务： Acceptance 接受The Employer has by signing below, accepted the Contractors offer and agre

30、es that in consideration for the execution of the Works by the Contractor, the Employer shall pay the contractor in accordance with the Contractor. This Agreement comes into effect on the date when the contractor receives one original of this document signed by the Employer.Signature: Date: Name: Au

31、thorized to sign on behalf of (organization name): Capacity: 雇主通过以下签字接受承包商报价，并鉴于承包商对工程实施同意按照合同向承包商付款。本协议书从承包商收到雇主签字本文件一份原件日期开始生效。签字： 日 期： 姓名： 受权代表： （组织名称） 签字职务： Appendix 附录This Appendix forms part of the Agreement 本附录构成协议书一部分。Note: with the exception of the items for which the Employers requirements

32、 have been inserted, the Contractor shall complete the following information before submitting his offer.（注：除已填入雇主要求项目外，承包商应在提交其报价前填写下列内容） Item 项目 Sub-Clause 条款号Data 内容 Documents forming the Contract listed in the order of priority 按优先次序列出构成合同文件：1.1.1Document (delete if not applicable) 文件（如不适用可删除）：D

33、ocument Identification 文件标题(a)The Agreement 协议书 (b)Particular Conditions 专用条件 (c)General Conditions 通用条件 (d)The specification 规范要求 (e)The drawings 图纸 (f)The Contractors tendered design 承包商投标设计 (g)The bill of quantities 工程量表 (h) (i) Time for Completion 竣工时间 1.1.9 days 天Law of the Contract 合同适用法律1.4La

34、w of the country*项目所在国法律Language 语言1.5 Provision of Site 现场提供2.1On the Commencement Date*在开工日期 Authorized person 受权人员3.1 Name and address of Employers representative (if known) 雇主代表姓名和地址（如知道）3.2 Performance security (if any) 履约担保（如果有）Amount 金额 4.4 Form 格式4.4 (details)(细节)Requirements for Contractors

35、 design (if any)对承包商设计要求（如果有）5.1Specification Clause Nos 规范要求条款号 Programme进度计划:Time for submission提交时间7.2Within 14 days* of the Commencement Date开工日期后14*天内Form of programme进度计划格式7.2 Amount payable due to failure to complete 由于未能完成工程应偿付金额7.4 per day up to a maximum of 10%* of sum stated in the Agreem

36、ent每天 ，超过协议书注明总额10%*Period for notifying defects缺陷通知期限9.1&11.5365 days* calculated from the date stated in the notice under Sub-Clause 8.2从根据第8.2款发出通知书中注明日期开始计算365*天内Variation procedure变更程序Daywork rates 计日工作费率10.2 (details)（细目）Valuation of the Works*工程估价*Lump sum Price总额价格11.1 (details) （细目）Lump sum

37、 price with schedules of rates 总额价格付费率表11.1 (details) （细目）Lump sum price with bill of quantities 总额价格附工程量表11.1 (details) （细目）Remeasurement with tender bill of quantities用投标工程量表再测量11.1 (details) （细目）Cost reimbursable 可补偿费用11.1 (details) （细目）Percentage of value of Materials and Plant 材料和生产设备价值百分比11.2M

38、aterials 80%*Plant 90%*Percentage of retention保留金百分比11.3 5%Currency of payment支付货币11.7Rate of interest 利率11.8 % per annum每年 Insurances 保险14.1Type of cover*保险类型 Amount of cover*保险金额 Exclusions*除外责任 The Works Materials, Plant and fees工程、材料、生产设备和费用The sum stated in the Agreement plus 15%协议书中注明总额加15% Co

39、ntractors Equipment承包商设备Full replacement cost全部重置成本 Third Party injury to persons and damage to property第三方人身伤害和财产损坏 Workers工人 Other cover*其他险 Arbitration仲裁Rules规则15.3UNCITRAL Arbitration Rules* (details)联合国国际贸易法委员会仲裁规则（细节）Appointing authority 负责任命机构15.3President of FIDIC or his nominee* (details)菲迪克（FIDIC）主席或他指定人*（细节）Place of Arbitration仲裁地点15.3The Country*工程所在国*Employer to amend as appropriate *表示适