2022年菲迪克简明合同格式-中英对照版 .pdf

《2022年菲迪克简明合同格式-中英对照版 .pdf》由会员分享，可在线阅读，更多相关《2022年菲迪克简明合同格式-中英对照版 .pdf（25页珍藏版）》请在淘文阁 - 分享文档赚钱的网站上搜索。

1、菲迪克（FIDIC）文献译丛中英文对照本国际咨询工程师联合会编译中 国 工 程 咨 询 协 会1999年第 1 版Agreement 协议书General Conditions 通用条件Rules for Adjudication裁决规则Notes for Guidance 指南注释Short Form of Contract 简明合同格式吕文学陈永强翻译唐萍校译王川徐礼章唐萍审订（1999年第 1版）（中英文对照本）（译者对译文的准确度承担全部责任，正式使用发生的争端，以英文原版为准）机 械 工 业 出 版 社名师资料总结-精品资料欢迎下载-名师精心整理-第 1 页，共 25 页 -2/25

2、菲迪克（FIDIC）授权书I herewith authorize CNAEC to translate FIDICs publications(but not the publications as edited by other organizations)intoChinese and publish them.I agree with your statement,as part of the agreement,that you will:a)Provide FIDIC with 10 copies of the translation per document,and b)Make

3、 a statement on the inside cover of the translation that the translator takes full responsibility for the accuracy of the translation and that in case of dispute,the original version in English shall prevail.Peter van der TOGT Publications manager 译文 在此，我授权中国工程咨询协会把FIDIC出版物译成中文并出版（但是，不包括其他组织编写的出版物）。

4、我同意你们的意见，作为协议的一部分，你们应：a)向 FIDIC提供每份文件中译本10本；b)在译文的扉页上注明译者对译文的准确度承担全部责任，如果发生争端，以英文原版为准。出版经理：Peter van der TOGT FIDIC is the French acronym for the International Federation of Consulting Engineers.FIDIC（中译菲迪克）是国际咨询工程师联合会的法文缩写。FIDIC was founded in 1913 by three national associations of consulting engin

5、eers within Europe.The objectives of forming the federation were to promote in common the professional interests of the member associations and to disseminate information of interest to members of its component national associations.菲迪克（FIDIC）是由欧洲三个国家的咨询工程师协会于1913年成立的。组建联合会的上的是共同促进成员协会的职业利益，以及向其成员协会

6、会员传播有益信息。Today FIDIC membership numbers more than 60 countries from all parts of the globe and the federation represents most of the private practice consulting engineers in the world.今天，菲迪克（FIDIC）已有来自全球各地60多个国家成员协会，代表着世界上大多数私人执业咨询工程师。FIDIC arranges seminars,conferences and other events in the furth

7、erance of its goals:maintenance of high ethical and professional standards;exchange of views and information;discussion of problems of mutual concern among member associations and representatives of the international financial institutions;and development of the consulting engineering industry in de

8、veloping countries.菲迪克（FIDIC）举办各类研讨会、会议及其他活动，以促进其目标：维护高的道德和职业标准；交流观点和信息；讨论成员协会和国际金融机构代表共同关心的问题，以及发展中国家工程咨询业的发展。FIDIC publications include proceedings of various conferences and seminars,information for consulting engineers,project owners and international development agencies,standard pre-qualificat

9、ion forms,contract documents and client/consultant agreements.They are available from the secretariat in Switzerland.菲迪克（FIDIC）的出版物包括：各类会议和研讨会的文件，为咨询工程师、项目业主和国际开发机构提供的信息，资格预审标准格式，合同文件以及客户与工程咨询单位协议书。这些资料可以从设在瑞士的菲迪克（FIDIC）秘书处得到。国际咨询工程师联合会INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS 名师资料总结-精品资料欢迎下载

10、-名师精心整理-第 2 页，共 25 页 -3/25FOREWORD 前言These Conditions of Contract have been prepared by the INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS（FIDIC）and are recommended for engineering and building work of relatively small capital value.However,depending on the type of work and the circumstances,the C

11、onditions may be suitable for contracts of greater value.They are considered most likely to be suitable for fairly simple or repetitive work or work short duration without the need for specialist sub-subtract.国际咨询工程师联合会（FIDIC菲迪克）已编写本合同条件，建议用于投资金额相对较小的工程项目和建筑工程。根据工程的类型和具体情况，也可以适用于金额较大的合同。本条件可能最适用于不需进

12、行专业分包的相当简单或重复性的工程或工期短的工程。The main aim has been to produce a straightforward flexible document which includes all essential commercial provisions and which may be used for all types of engineering and building work with a variety of administrative arrangements.Under the usual arrangements for this ty

13、pe of contract,the Contractor constructs the Works in accordance with design provided by the Employer or by his representative(if any).However,this form may also be suitable for contracts which include,or wholly comprise,contractor-designed civil,mechanical and/or electrical works.主要上的是编出一个简明、灵活的文件，

14、包括所有主要的商务条款，可用于多种管理方式的各类工程项目和建筑工程。这种合同的通常情况是，由承包商按照雇主或其代表（如果有）提供的设计实施工程。这种格式也可用于包括或全部由承包商设计的土木、机械和/或电气工程合同。In addition,the Employer has a choice of valuation methods.Furthermore,although there is no reference to an impartial Engineer,the Employer may appoint an independent Engineer to act impartiall

15、y,should he wish to do so.另外，雇主可以选择估价方法。还有，尽管没有提到公正的工程师，如果雇主想聘用一个独立的工程师公平行事，他可以这么做。The form is recommended for general use,though modifications may be required in some jurisdictions.FIDIC considers the official and authentic text to the version in the English language.建议本格式可供通用，便在某些司法管辖区可能需要一些修改。菲迪克

16、认为正式的和权威性的文本应是英文版本。The intention is that all necessary information should be provided in the Appendix to the Agreement,the latter incorporating the tenderer s offer and its acceptance in one simple document.The General Conditions are expected to cover the majority of contracts.Nevertheless,users wil

17、l be able to introduce Particular Conditions if they wish,to cater for special cases or circumstances.The General Conditions and the Particular Conditions will together comprise the conditions governing the rights and obligations of the parties.编写意图是所有必要的信息应在协议书的附录中给出，协议书把投标人的报价和雇主的接受编入一个简单的文件。通用条件应

18、能覆盖多数合同，如果用户需要，他们可以加入专用条件以适应特定情况或条件的需要。通用条件和专用条件将一起构成决定各方权利和义务的条件。To assist in the preparation of tender documents using these Conditions,Notes for Guidance are included.These Notes will not become one of the documents forming the Contract.Finally,applicable Rules for Adjudication are also included.

19、为了有助于使用本条件编制招标投标文件，还包括了指南注释。这些注释不是组成合同的一个文件。最后，还列入了适用的裁决规则。The attention of users is drawn to the FIDIC publication“Tendering Procedure”,which presents a systematic approach to the selection of tenderers and the obtaining and evaluation of tenders.用户请注意菲迪克（FIDIC）编写出版的招标程序，它提供了选择投标人、招标和评标的系统方法。名师资料总结

20、-精品资料欢迎下载-名师精心整理-第 3 页，共 25 页 -4/25目录Agreement 协议书 .6 Offer 报价 .6 Acceptance 接受.6 Appendix 附录.7 General Conditions 通用条件 .9 1 General Provisions 一般规定 .9 1.1 Definitions 定义.9 1.2 Interpretation 解释.11 1.3 Priority of Documents 文件优先次序 .11 1.4 Law 法律.11 1.5 Communications 通信交流 .11 1.6 Statutory Obligatio

21、ns 法定义务 .11 2 The Employer 雇主 .12 2.1 Provision of Site 现场的提供 .12 2.2 Permits and Licences 许可和执照.12 2.3 Employer s Instructions 雇主的指示.12 2.4 Approvals 批准 .12 3 Employer s Representatives 雇主代表.12 3.1 Authorized Person 受权人.12 3.2 Employer s Representative 雇主代表.13 4 The Contractor 承包商 .13 4.1 General O

22、bligations 一般义务.13 4.2 Contractor s Representative 承包商代表.13 4.3 Subcontracting 分包 .13 4.4 Performance Security 履约担保.13 5 Design by Contractor 由承包商设计.14 5.1 Contractor s Design承包商的设计.14 5.2 Responsibility for Design.14 6 Employer s Liabilities 雇主的责任 .14 6.1 Employer s Liabilities 雇主的责任.14 7 Time for

23、Completion 竣工时间.15 7.1 Execution of the Works 工程的实施 .15 7.2 Programme 进度计划 .16 7.3 Extension of Time 延长期 .16 7.4 Late Completion 延迟竣工.16 8 Taking-Over 接收 .16 8.1 Completion 竣工.16 8.2 Taking-Over Notice 接收通知.16 9.Remedying Defects 修补缺陷 .17 9.1 Remedying Defects 修补缺陷.17 名师资料总结-精品资料欢迎下载-名师精心整理-第 4 页，共

24、25 页 -5/259.2 Uncovering and Testing 除去覆盖和试验.17 10.Variations and Claims 变更和索赔.17 10.1 Right to Vary 变更权.17 10.2 Valuation of Variations 变更的估价.18 10.3 Early Warning 提早通知.18 10.4 Right to Claim 索赔权.18 10.5 Variation and Claim Procedure 变更和索赔程序.18 11.Contract Price and Payment 合同价格和付款.19 11.1 Valuatio

25、n of the Works 工程的估价.19 11.2 Monthly Statements 月报表 .19 11.43 Interim Payment 期中付款 .19 11.4 Payment of First Half of Retention 前一半保留金的支付.19 11.5 Payment of Second Half of Retention 后一半保留金的支付.20 11.6 Final Payment 最终付款 .20 11.7 Currency 货币.20 11.8 Delayed Payment 延误的付款 .20 12.Default 违约 .20 12.1 Defa

26、ult by Contractor.20 12.2 Default by Employer 雇主违约.21 12.3 Insolvency 无力偿债 .21 12.4 Payment upon Termination 终止的付款.21 13.Risk and Responsibility 风险和职责.22 13.1 Contractor s Care of the Works 承包商的工程照管.22 13.2 Force Majeure 不可抗力.22 14.Insurance 保险.23 14.1 Extent Cover 保险范围.23 14.2 Arrangements 约定 .23 1

27、4.3 Failure to Insure 未能办理保险.24 15.Resolution of Disputes 争端的解决 .24 15.1 Adjudication 裁决 .24 15.2 Notice of Dissatisfaction 表示不满的通知.24 15.3 Arbitration 仲裁.25 Particular Conditions 专用条件.25 名师资料总结-精品资料欢迎下载-名师精心整理-第 5 页，共 25 页 -6/25Agreement 协议书The Employer is of The Contractor is of The Employer desir

28、es the execution of certain Works known as 雇主是：的承包商是：的雇主要实施的工程名称为Offer 报价The Contractor has examined the documents listed in the Appendix which forms part of this Agreement and offers to execute the Works in conformity with the Contract for the sum of(in words)(in figures)()or such other sum as may

29、be ascertained under the Contract.This offer,of which the Contractor has submitted two signed originals,may be accepted by the Employer by signing and returning one original of this document to the Contractor before(date)The Contractor understands that the Employer is not bound to accept the lowest

30、or any offer received for the Works.Signature:Date:Name:Authorized to sign on behalf of(organization name):Capacity:承包商已研究了构成本协议书一部分的列于附录中的文件，按照合同实施该工程所报价格为(大写)(小写)()或根据合同可能确定的此类其他总额。承包商已提交两份本报价的签字原件，雇主可通过签字和将本文件一份原件于(日期)前返还给承包商予以接受。承包商理解雇主不一定必须接受收到的对该工程的最低的或任何报价。签字：日期：姓名：受权代表：（组织名称）签字职务：Acceptance

31、接受The Employer has by signing below,accepted the Contractor s offer and agrees that in consideration for the execution of the Works by the Contractor,the Employer shall pay the contractor in accordance with the Contractor.This Agreement comes into effect on the date when the contractor receives one

32、original of this document signed by the Employer.Signature:Date:Name:Authorized to sign on behalf of(organization name):Capacity:雇主通过以下签字接受承包商的报价，并鉴于承包商对工程的实施同意按照合同向承包商付款。本协议书名师资料总结-精品资料欢迎下载-名师精心整理-第 6 页，共 25 页 -7/25从承包商收到雇主签字的本文件一份原件的日期开始生效。签字：日期：姓名：受权代表：（组织名称）签字职务：Appendix 附录This Appendix forms pa

33、rt of the Agreement 本附录构成协议书的一部分。Note:with the exception of the items for which the Employer s requirements have been inserted,the Contractor shall complete the following information before submitting his offer.（注：除已填入雇主要求的项目外，承包商应在提交其报价前填写下列内容）Item 项目Sub-Clause 条款号Data 内容Documents forming the Contr

34、act listed in the order of priority 按优先次序列出构成合同的文件：1.1.1 Document(delete if not applicable)文件（如不适用可删除）：Document Identification 文件标题(a)The Agreement 协议书 (b)Particular Conditions 专用条件 (c)General Conditions 通用条件 (d)The specification 规范要求 (e)The drawings 图纸 (f)The Contractor s tendered design 承包商的投标设计(g

35、)The bill of quantities 工程量表 (h)(i)Time for Completion 竣工时间 1.1.9 days 天Law of the Contract 合同适用法律 1.4 Law of the country*项目所在国法律Language 语言 1.5 Provision of Site 现场的提供 2.1 On the Commencement Date*在开工日期Authorized person 受权人员 3.1 Name and address of Employers representative(if known)雇主代表的姓名和地址（如知道）3

36、.2 Performance security(if any)履约担保（如果有）Amount 金额 4.4 Form 格式 4.4(details)(细节)Requirements for Contractor s design(if any)对承包商设计的要求（如果有）5.1 Specification Clause No s 规范要求条款号Programme进度计划:Time for submission 提交时间7.2 Within 14 days*of the Commencement Date 开工日期后14*天内Form of programme 进度计划的格式7.2 名师资料总结

37、-精品资料欢迎下载-名师精心整理-第 7 页，共 25 页 -8/25Amount payable due to failure to complete 由于未能完成工程应偿付金额7.4 per day up to a maximum of 10%*of sum stated in the Agreement 每天，超过协议书注明总额的10%*Period for notifying defects 缺陷通知期限9.1&11.5 365 days*calculated from the date stated in the notice under Sub-Clause 8.2 从根据第 8.

38、2 款发出的通知书中注明的日期开始计算365*天内Variation procedure 变更程序Daywork rates 计日工作费率10.2(details)（细目）Valuation of the Works*工程的估价*Lump sum Price 总额价格11.1(details)（细目）Lump sum price with schedules of rates 总额价格付费率表11.1(details)（细目）Lump sum price with bill of quantities 总额价格附工程量表11.1(details)（细目）Remeasurement with t

39、ender bill of quantities 用投标工程量表再测量11.1(details)（细目）Cost reimbursable 可补偿费用11.1(details)（细目）Percentage of value of Materials and Plant 材料和生产设备价值的百分比11.2 Materials 80%*Plant 90%*Percentage of retention 保留金百分比11.3 5%Currency of payment 支付货币11.7 Rate of interest 利率11.8%per annum每年Insurances 保险14.1 Type

40、 of cover*保险类型Amount of cover*保险金额Exclusions*除外责任The Works Materials,Plant and fees工程、材料、生产设备和费用The sum stated in the Agreement plus 15%协议书中注明的总额加 15%Contractor s Equipment承包商设备Full replacement cost 全部重置成本Third Party injury to persons and damage to property第三方人身伤害和财产损坏Workers工人Other cover*其他险Arbitra

41、tion仲裁Rules规则15.3 UNCITRAL Arbitration Rules*(details)联合国国际贸易法委员会仲裁规则（细节）Appointing authority 负责任命机构15.3 President of FIDIC or his nominee*(details)菲迪克（FIDIC）的主席或他指定的人*（细节）Place of Arbitration 仲裁地点15.3 The Country*工程所在国*Employer to amend as appropriate*表示适当时由雇主修改。名师资料总结-精品资料欢迎下载-名师精心整理-第 8 页，共 25 页

42、-9/25General Conditions 通用条件1 General Provisions 一般规定1.1 Definitions 定义In the Contract as defined below,the words and expressions defined shall have the following meanings assigned to them,except where the context requires otherwise:在下文定义的合同中，除上下文另有要求外，定义所列的词语或措辞应具有下列给定的含义：The Contract 1.1.1“Contrac

43、t”means the Agreement and the other documents listed in the Appendix.合同“合同”系指协议书以及附录中所列的其他文件。1.1.2“Specification”means the document as listed in the Appendix,including Employer s requirements in respect of design to be carried out by the Contractor,if any,and any Variation to such drawings.“规范要求”系指附

44、录中所列的，包括关于要由承包商进行的设计的雇主要求的文件（如果有），以及对此类文件的任何变更。1.1.3“Drawings”means the Employer s drawings of the Works as listed in the Appendix,and any Variation to such drawings.“图纸”系指附录中所列雇主的工程图纸，以及对此类图纸的任何变更。Persons 1.1.4“Employer”means the person named in the Agreement and the legal successors in the title t

45、o this person,but not(except with the consent of the Contractor)any assignee.当事人“雇主”系指协议书中指名的当事人和取得此当事人资格的合法继承人，但不指其任何受让人（除经承包商同意外）。1.1.5“Contractor”means the person named in the Agreement and the legal successors in title to this person,but no(except with the consent of the Employer)any assignee.“承

46、包商”系指协议书中指名的当事人和取得此当事人资格的合法继承人，但不指其任何受让人（除经雇主同意外）。1.1.6“Party”means either the Employer or the Contractor.“当事方”指雇主或承包商。Dates,Times and Periods 日期、时间和期限1.1.7“Commencement Date”means the date 14 days after the date the Agreement comes into effect or any other date agreed between the Parties.“开工日期”系指协议

47、书生效日期后第14 天的日期，或双方同意的其他任何日期。1.1.8“Day”means a calendar day.“天”指日历日。名师资料总结-精品资料欢迎下载-名师精心整理-第 9 页，共 25 页 -10/251.1.9“Time for Completion”means the time for completing the Works as stated in the Appendix(or as extended under Sub-Clause 7.3),calculated from the Commencement Date.“竣工时间”系指附录中注明的、从开工日期算起的完

48、成工程的时间（或根据第7.3款的规定延长后的时间）。Money and Payments 款项和支付1.1.10“Cost”means all expenditure property incurred(or to be incurred)by the Contractor,whether on or off the Site,including overheads and similar charges,but does not include profit.“成本（费用）”指承包商在现场内或现场外合理发生（或将发生）的全部支出，包括管理费用和类似开支，但不包括利润。Other Defini

49、tions 其他定义1.1.11“Contractor s Equipment”means all apparatus,machinery,vehicles,facilities and other things required for the execution of the Works but does not include Materials or Plant.“承包商设备”系指为实施工程需要的全部仪器、机械、车辆、设施和其他物品，但不包括材料或生产设备。1.1.12“Country”means the country in which the Site is located.“工程

50、所在国”系指现场所在的国家。1.1.13“Employer s Liabilities”means those matters listed in Su-Clause 6.1.“雇主的责任”系指第6.1款中所列的内容。1.1.14“Force Majeure”means an exceptional event or circumstance:which is beyond a Partys control;which such Party could not reasonably have provided against before entering into the Contract;