2023年工地工程承包合同协议书样本大全(精选9篇).docx

《2023年工地工程承包合同协议书样本大全(精选9篇).docx》由会员分享，可在线阅读，更多相关《2023年工地工程承包合同协议书样本大全(精选9篇).docx（102页珍藏版）》请在淘文阁 - 分享文档赚钱的网站上搜索。

1、2023年工地工程承包合同协议书样本大全(精选9篇)篇一：工地工程承包合同协议书样本大全 电子监控工程合同 签定地点：xx市江北区电教教仪站 签订时间：?年?月?日 甲方：xx市xx试验中学 乙方： 按照中华人民共和国民法典，遵循平等、自愿、公平和诚信的原则，双方就本建设工程施工事项协商一致，订立本合同。 一、工程概况 工程名称：xx市xx试验中学电子监控工程 工程地点：xx市xx试验中学校内内 工程范围：详见xx市xx试验中学监控系统招标文件和投标书 工程内容：监控系统布线、设备安装及调试 二、工程总价：详见附件1(工程价格汇总表) 合同金额：人民币贰拾捌万壹仟肆佰玖拾伍元整(￥281495

2、.00?元)。 注：工程总款中，中标工程总款为264845.00元，后续附加四画面分割器16650.00元?，为甲、乙方及江北区电教教仪站认可，为必需附加项，见工程价格汇总表第9项。 本工程在学校监控系统工程招标文件、投标书范围内采纳总价包干的形式，一次包干;超出学校监控系统工程招标文件、投标书范围内的项目若学校需要增加，由双方协商定价。 三、产品质量及安装调试要求： 1、乙方须按附表1要求向甲方提供符合国家产品质量标准的正品设备，不得以任何理由以次充好，如发觉有非正品则乙方以一赔十。未经甲方同意，不得随便更改方案。并提供各设备有关品质证明书，合格证，说明书，相关软件等资料。 2、乙方所提供合

3、同内设备应保证产品内外包装完好无损，若不能到达要求，甲方有权要求乙方马上更换合格产品直至解除合同。由此带来的一切损失由乙方负责。 3、在签订合同后，乙方根据甲方要求负责设备安装、调试，要求做到布局合理，布线规范，便于使用及维护，符合国家有关技术标准。 4、由甲方提供安装场地及电源。 四、技术标准及质量保证 (1)布线标准：乙方监控系统布线施工，严格遵照国际民用闭路电视监控系统技术规范gb50198-94. (2)乙方所供设备均以生产厂家提供的产品技术资料为技术标准。 (3)乙方保证本项目所供产品均为合同中指定的产品，且包装为原包装。产品进场时提供供货证明，经甲方验收后进行施工。 (4)乙方对监

4、控布线、设备质保见附件1(工程价格汇总表质保说明) 五、工程项目建设期限： 合同签定后5日内进场施工，整个施工工期?30?天。(XX年7月26日开工，XX年8月26日以前乙方按设计要求完成设备安装调试。并能投入正常使用。) 六、售后服务： 1、乙方所提供合同内设备，从验收之日起，全部产品及零配件质保期按投标书规定办理。在质保期内，若有产品质量问题，由乙方负责免费更换或修理。质保期满后，设备修理时，乙方按本钱费计算。更换的产品必需是新的，且质保期限从当时算起。 2、凡由产品质量问题引起的各类故障，乙方在接到甲方故障报修通知后，在4小时内响应，24小时内解决故障，若在24小时内不能排除故障的，则应

5、由乙方提供不低于原设备标准的备用产品保证学校的正常行课。 4、乙方向甲方免费培训1-2名设备操作管理人员，要求到达能正确使用与维护本合同的设施、设备。 七、竣工验收及付款方式： 项目施工安装、调试完毕，由乙方通知甲方组织验收，并提供相应完好的验收资料。乙方自书面通知之日起，10天内由于甲方拖延不验收视为工程验收合格。 项目施工安装、调试完毕后，由江北区电教站与学校一道组织验收，并签注验收结论。自验收合格之日起5日内支付合同总金额的10%?(￥28149.50)，使用一年后(即XX年内无质量问题和用户投诉的支付合同总金额的30?%(￥84448.50)(此部分资金不计算利息)，使用二年后(即XX

6、年内)无质量问题和用户投诉的支付合同总金额的60%(￥168897.00)(此部分资金不计算利息)，逾期不付按0.1%支付滞纳金。 八、商定事项 为确保工期，争取提前竣工，由甲乙双方共同组成工程实施小组。 合同如需变更，甲、乙双方另行协商确定变更事宜，双方签章生效，并作为本合同的附件。 招标文件、投标书是本合同的一部分，具有同等法律效力。 附件1作为本合同要件，乙方必需遵照执行，否则视为违约。 九、违约责任： 1、乙方必需严格按合同要求按时、按质(即合同要求的设备的规格、型号)、按量完成供货与安装调试完毕并交付甲方使用。如有违约，每违约一天，按合同总金额的0.1%甲方支付违约金;若违约超过10

7、天，甲方有权解除合同，所造成的损失，由乙方负责。 2、在乙方履行合同后，甲方保证按时向乙方支付合同款项，如有违约，每违约一天，按合同总金额的0.1%向乙方支付违约金。 十、本合同按中华人民共和国民法典，中华人民共和国产品质量法，消费者权益爱护法等有关法律条款执行。 十一、合同执行中，若发生纠纷，由甲乙双方协商解决，若协商不成，提交仲裁委员会解决，直至提交法院审理。 十二、施工期间出现工伤事故，由施工单位自行负责。 十三、本合同一式四份，由甲方执二份(存档一份，财务一份)，乙方执一份，电教站备案一份。 十四、未尽事宜，由甲乙双方友好协商解决。 十五、本合同经双方法定代表人或其授权的代表签字，加盖

8、双方公章后之日生效。货款两清后，合同效力终止。 甲方：xx市xx试验中学?乙方： 法定代表人：?法定代表人： 经办人：?经办人： 年?月?日 篇二：工地工程承包合同协议书样本大全 国际土木工程建筑承包合同 PART工GENERAL?CONDITIONS 第一章?总则 DEFINITIONS?AND?INTERPRETATION 定义和释义 11In?the?Contract，as?hereinafter?defined，the?following?words?and?expressions?shall?have?the?meanings?hereby?assigned?to?them，exce

9、pt?where?the?context?otherwise?requires： 11在本合同中，除按上下文另具意义者外，以下词语应解释如下： aEmployer?means?the?party?named?in?Part?II?who?will?employ?the?Contractor?and?the?legal?successors?in?title?to?the?Employer，but?not，except?with?the?consent?of?the?Contractor，any?assignee?of?the?Employer “业主指第二章中所指定的雇用承包人的一方或其权利继

10、承人，但不包括业主的受让人，经承包人同意者除外。 b“Contractormeans?the?person?or?persons，firm?or?company?whose?tender?has?been?accepted?by?the?Employerand?includes?the?Contractors?personal?representatives，successors?and?permitted?assigns “承包人指标书已被业主接受的某个或某些人、商行或公司，包括其个人代表，继承人和业经认可的受让人。 c“Engineermeans?the?Engineer?designat

11、ed?as?such?in?Part?II，or?other?Engineer?appointed?from?time?to?time?by?the?Employer?and?notified?in?writing?to?the?Contractor?to?act?as?Engineer?for?the?purposes?of?the?Contract?in?place?of?the?Engineer、designated “工程师指第二章中所指定的工程师，或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其他工程师。 d)?Engineers?Representative?mea

12、ns?any?resident?engineer?or?assistant?of?the?Engineer?or?any?clerk?of?works?appointed?from?time?to?time?by?the?Employer?or?the?Engineer?to?perform?the?duties?set?forth?in?Clause?2?hereof，whose?authority?shall?be?notified?in?writing?to?the?Contractor?by?the?Engineer “工程师代表指任何常驻工程技术人员、工程师助手，或由业主或工程师随时

13、任命履行本合同第二条规定职责的任何工程现场监督，其权限应由工程师书面通告承包人。 e)?“Works?shall?include?both?Permanent?Works?and?Temporary?Works， “工程包括永久性工程和临建工程。 f“Contract?means?the?Conditions?of?Contract，specification，Drawings，priced?Bill?of?Quantities，Schedule?of?Rates?and?Prices，if?any，Tender，Letter?of?Acceptance?and?the?Contract?Ag

14、reement，if?completed “合同指合同条款、技术规范、图纸、标价的建筑工程清单、单价和价格表假如有，还可指标书、接受证书以及承包协议如已完成。 g)?“Contract?Price?means?the?sum?named?in?the?Letter?of?Acceptance,?subject?to?such?additions?thereto?or?deductions?therefrom?as?may?be?made?under?the?provisions?hereinafter?contained “合同价格指在接受证书中确定的数额，可按本合同以下条款规定增减。 h)“

15、Constructional?Plant?means?all?appliances?or?things?of?whatsoever?nature?required?in?or?about?the?execution?or?maintenance?of?the?Works?but?does?not?include?materials?or?other?things?intended?to?form?or?forming?part?of?the?Permanent?Works “建筑设备指工程施工和修理中或有关施工和修理所需的全部设备或物品，不管任何性质，但不包括旨在构成或正在构成永久性工程某一部

16、分的材料或其他物品。 i“Temporary?Works?means?all?temporary?works?of?every?kind?required?in?or?about?the?execution?or?maintenance?of?the?Works “临建工程指工程施工或修理或有关工程施工或修理所需的各种临时工程。 j“Permanent?Worksmeans?the?permanent?works?to?be?executed?and?maintained?in?accordance?with?the?Contract “永久性工程指按合同将施工和修理的永久工程。 k?“Spe

17、cification?means?the?specification?referred?to?in?the?Tender?and?any?modification?thereof?or?addition?thereto?as?may?from?time?to?time?be?furnished?or?approved?in?writing?by?the?Engineer “技术规范指在标书或任何标书更改中提及的规范，或由工程师随时可能增加或书面同意增加的部分。 1“Drawings?means?the?drawings?referred?to?in?the?Specification?and?

18、any?modification?of?such?drawings?approved?in?writing?by?the?Engineer?and?such?other?drawings?as?may?from?time?to?time?be?furnished?or?approved?in?writing?by?the?Engineer “图纸指技术规范中规定的图纸，经工程师书面同意对此种图纸所作的任何更改，以及可由工程师随时提供或书面认同的其他图纸。 m?“Site?means?the?land?and?other?places?on，under，in?or?through?which?t

19、he?Permanent?Works?or?Temporary?Works?designed?by?the?Engineer?are?to?be?executed?and?any?other?lands?and?places?provided?by?the?Employer?for?working?space?or?any?other?purpose?as?may?be?apecifically?designated?in?the?Contract?as?forming?part?of?the?Site “工地指工程师设计的永久性或临建工程施工所需的土地及其他场地，包括地面、地下、在之上或通过

20、部分，以及由业主所提供的用作临时储存或其他目的的其他土地或场所，只要能按合同明文规定构成工地的组成部分。 n“Approved?means?approved?in?writing，including?subsequent?written?confirmation?ofprevious?verbalapproval?and“approval?means?approval?in?writing，including?as?aforesaid 2Words?importing?the?singular?only?also?include?the?plural?and?vice?versa?where?

21、the?context?requires? 12按合同上下文所需，单数含义的单词也可具有复数的含义，反之一样。 3The?headings?and?marginal?notes?in?these?Conditions?of?Contract?shall?not?be?deemed?to?be?part?thereof?or?be?taken?into?consideration?in?the?interpretation?or?construction?thereof?or?of?the?Contract 13合同条款的标题和边注不得视为合同的一部分，不得用于考虑解释条款或合同。 4The?w

22、ord“cost?shall?be?deemed?to?include?overhead?costs?whether?on?or?off?the?Site 14“费用一词应视为含工地上或以外发生的间接费用。 ENGINEER?AND?ENGINEERS?REPRFSFNTATIVE 工程师及工程师代表 21The?Engineer?shall?carry?out?such?duties?in?issuing?decisions，certificates?and?orders?as?are?specified?in?the?ContractIn?the?event?of?the?Engineer

23、?being?required?in?terms?of?his?appointment?by?the?Employer?to?obtain?the?specific?approval?of?the?Employer?for?the?execution?of?any?part?of?these?duties，this?shall?be?set?out?in?Part?II?of?these?Conditions 21工程师必需按合同明文规定，履行作决断、颁发证书和发出指令等职责。如业主签发的工程师任命书中规定其某些职责的履行得经业主特地认可，其要件应在本合同第二部分予以规定。 2The?Engi

24、neer?may?from?time?to?time?in?writing?delegate?to?the?Engineers?Representative?any?of?the?powers?and?authorities?vested?in?the?Engineer?and?shall?furnish?to?the?Contractor?and?to?the?Employer?a?copy?of?all?such?written?delegations?of?powers?and?authorities?Any?written?instruction?or?approval?given?b

25、y?the?Engineers?Representative?to?the?Contractor?within?the?terms?of?such?delegation，but?not?otherwise，shall?bind?the?Contractor?and?the?Employer?as?though?it?had?been?given?by?the?EngineerProvided?always?as?follws： 22工程师可随时书面授权其代表代行其任何职权，但必需将全部此种授权书的副本提交给承包人和业主。在授权期间，工程师代表给承包人的任何书面指令或认可仅限于此对承包人和业主具

26、有与工程师的指令或认可同样的效力。以下规定属于例外： a?Failure?of?the?Engineers?Representative?to?disapprove?any?work?or?materials?shall?not?prejudice?the?power?of?the?Engineer?thereafter?to?disapprove?such?work?or?materials?and?to?order?the?pulling?down，removal?or?breaking?up?thereof 工程师代表对任何工程或材料的不予否认，不得影响工程师此后否认以及指令拆毁、移动或

27、撤除此种工程或材料的权力。 bIf?the?Contractor?shall?be?dissatisfied?by?reason?of?any?decisions?of?the?Engineers?Representative?he?shall?be?entitled?to?refer?the?matter?to?the?Engineer，who?shall?thereupon?confirm，reverse?or?vary?such?decision 若承包人对工程师代表的任何确定不满意，其有权将此确定提交工程师确认、取消或更改。? ASSIGNMENT?AND?SUBLETTING 转让和

28、分包 3The?Contractor?shall?not?assign?the?Contract?or?any?part?thereof，or?any?benefit?or?interest?therein?or?thereunder，otherwise?than?by?a?charge?in?favor?of?the?Contractors?bankers?of?any?monies?due?or?to?become?due?under?this?Contract，without?the?prior?written?consent?of?the?Employer 3未经业主事前书面同意，承包

29、人不得将合同或其他任何部分，或合同所规定或依合同而产生的任何收益转让，向承包人的开户银行支付按本合同规定到期或即将到期的款项除外。 4The?Contractor?shall?not?sub-let?the?whole?of?the?WorksExcept?where?otherwise?provided?by?the?Contract，the?Contractor?shall?not?sub-let?any?part?of?the?Works?without?the?prior?written?consent?of?the?Engineer，which?shall?not?be?unreas

30、onably?withheld，and?such?consent，if?given，shall?not?relieve?thecontractor?from?any?liability?or?obligation?under?the?Contract?and?he?shall?be?responsible?for?the?acts，defaults?and?neglects?of?any?sub-contractor，his?agents，servants?or?workmen?as?fully?as?if?they?were?the?acts，defaults?or?neglects?of?

31、the?Contractor，his?agents?servants?or?workmenProvided?always?that?the?provision?of?labor?on?a?piecework?basis?shall?not?be?deemed?to?be?a?subletting?under?the?Clause 4承包人不得转包整个工程。除非合同另有规定，未经工程师事前书面同意，承包人也不得分包工程的任何部分，但工程师不得无故不同意分包，一旦同意分包，此种同意不得免去承包人所承当的任何合同所规定的责任或义务，他必需对任何分包人、其代理人、雇员或工人的行为、不履行和过失负完全责

32、任，犹如这些行为、不履行或过失是承包人、其代理人、雇员或工人所为。以计件方式提供劳力不得视为是本条所规定的分包。 CONTRACT?DOCUMENTS 合同文件 51There?shall?be?stated?in?Part?1I?of?these?Conditions： 51以下要件得在合同第二部分规定： athe?language?or?languages?in?which?the?Contract?documents?shall?be?drawn?up?and 用以起草合同文件的语言； bthe?country?or?state，the?law?of?which?is?to?apply?

33、to?the?Contract?and?according?to?which the?Contract?is?to?be?construed 合同适用哪个国家的法律以及用哪个国家的法律解释合同。 If?the?said?documents?are?written?in?more?than?one?language，the?language?according?to?which?the?Contract?is?to?be?construed?and?interpreted?shall?also?be?designated?in?Part?II，being?therein?designated?t

34、he?“Ruling?Language 假如文件用一种以上语言作成，用以解释合同的语言也必需在第二部分中规定，且将被寇为“主体语言。 2Except?if?and?to?the?extent?otherwise?provided?by?the?Contract，the?provisions?of?the?Conditions?of?Contract?Parts?and?shall?prevail?over?those?of?any?other?document?forming?part?of?the?ContractSubject?to?the?foregoing，the?several?do

35、cuments?forming?the?Contract?are?to?be?taken?as?mutually?explanatory?of?one?another，but?in?case?of?ambiguities?or?discrepancies?the?same?shall?be?explained?and?adjusted?by?the?Engineer?who?shall?thereupon?issue?to?the?Contractor?instructions?thereonProvided?always?that?if，in?the?opinion?of?the?Engin

36、eer，compliance?with?any?such?instructions?shall?involve?the?Contractor?in?any?cost，which?by?reason?of?any?such?ambiguity?or?discrepancy?could?not?reasonably?have?been?foreseen?by?the?Contractor，the?Engineer?shall?certify?and?the?Employer?shall?pay?such?additional?sum?as?may?be?reasonable?to?cover?su

37、ch?costs 61The?Drawings?shall?remain?in?the?sole?custody?of?the?Engineer，but?two?copies?thereof?shall?be?furnished?to?the?Contractor?free?of?chargeThe?Contractor?shall?provide?and?make?at?his?own?expense?any?further?copies?required?by?himAt?the?completion?of?the?Contract?the?Contractor?shall?return?

38、to?the?Engineer?all?Drawings?provided?under?the?Contract 61图纸由工程师单独保管，但须向承包人免费提供两份副本。承包人所需的其余副本由他自己制作并承当费用。合同履行后，承包人须将全部合同图纸归还工程师。 2One?copy?of?the?Drawings，furnished?to?the?Contractor?as?aforesaid，shall?be?kept?by?the?contractor?on?the?Site?and?the?same?shall?at?all?reasonable?times?be?available?fo

39、r?inspection?and?use?by?the?Engineer?and?the?Engineers?Representative?and?by?any?other?person?authorized?by?the?Engineer?in?writing 3The?Contractor?shall?give?written?notice?to?the?Engineer?whenever?planning?or?progress?of?the?Works?is?likely?to?be?delayed?or?disrupted?unless?any?further?drawing?or?

40、order，including?a?direction，instruction?or?approval，is?issued?by?the?Engineer?within?a?reasonable?timeThe?notice?shall?include?details?of?the?drawing?or?order?required?and?of?why?and?by?when?it?is?required?and?of?any?delay?or?disruption?likely?to?be?suffered?if?it?is?late 63如工程师不在适当时间内再提供图纸或指令，包括指示、

41、指令或认可，工程打算或进展便可能被延误或中断时，承包人必需书面通知工程师。通知书中应具体说明所需的图纸或指令，所需缘由和时间，以及假如不准时提供而可能造成的任何延误和中断。 4If，by?reason?of?any?failure?or?inability?of?the?Engineer?to?issue?within?a?time?reasonable?in?all?the?circumstances?any?drawing?or?order?requested?by?the?Contractor?in?accordance?with?subclause3of?this?Clause，the

42、?Contractor?suffers?delay?and/or?incurs?costs?then?the?Engineer?shall?take?such?delay?into?account?in?determining?any?extension?of?time?to?which?the?Contractor?is?entitled?under?Clause?44?hereof?and?the?Contractor?shall?be?paid?the?amount?of?such?cost?as?shall?be?reasonable? 64如承包人按本条第3款规定索要图纸或指令，由于

43、工程师没有或不能在合理时间内 提供，从而导致承包人误工和左戊承当费用，工程师必需考虑此种延误，以确定是否按本合同第44条规定延长承包人的工期，且只要有理由，承包人所承当的此种费用必需得到补偿。 7The?Engineer?shall?have?full?power?and?authority?to?supply?to?the?Contractor?from?time?to?time,?during?the?progress?of?the?Works，such?further?drawings?and?instructions?as?shall?be?necessary?for?the?purp

44、ose?of?the?proper?and?adequate?execution?and?maintenance?of?the?Works?The?Contractor?shall?carry?out?and?be?bound?by?the?same 7在施工期间，工程师全权负责随时进一步向承包人提供图纸和指示，以满足工程正常施工和维护所需。承包人必需执行且受图纸和指示的约束。 GENERAL?OBLIGATIONS 总义务 81The?Contractor?shall，subject?to?the?provisions?of?the?Contract，and?with?due?care?an

45、d?diligence,?execute?and?maintain?the?Works?and?provide?all?labor，including?the?supervision?thereof,?materials，Constructional?Plant?and?all?other?things，whether?of?a?temporary?or?permanent?nature，required?in?and?for?such?execution?and?maintenance，so?far?as?the?necessity?for?providing?the?same?is?spe

46、cified?in?or?is?reasonably?to?be?inferred?from?the?Contract 81承包人必需依据合同条款，对工程的施工和维护予以应有的留意，且提供此种施工和维护所必需的包括劳动管理在内的全部劳力、材料、施工成套设备及其他一切物品，不管其是临时或长期性质，只要合同明文规定需要或依据合同合理推断需要。 2The?Contractor?shall?take?full?responsibility?for?the?adequacy，stability?and?safety?of?all?site?operations?and?methods?of?construction，provided?that?the?Contractor?shall?not?be?responsible,?except?as?may?be?expressly?provided?in?the?Contract，for?the?design?or?specification?of?the?Permanent?Works，or?for?the?design?or?specif